CONSTRUCTION

Issue: General engineering contractor sues client for providing incomplete drawings and information, forcing it to delay project completion and pay liquidated damages.

Plaintiff strategy: Artists-at-Law prepare a bar graph as cumulative stacks of RFI's (Requests for Information) and Clarifications, demonstrating the continual delays and added costs that incomplete drawings imposed on the contractor.

__________________________________________________________________ Artists-at-Law • (510) 843-1510 • Contact mreeves@artists-at-law.com